Terms & Conditions.

1. Definitions

Client / You / Your: the individual or entity engaging Modello Construction

Modello / We / Us / Our: Modello Construction

Services: any service we provide (construction, renovation, project oversight, etc.)

Website: modello-construction.com and associated pages

2. Use of Website & Intellectual Property

All content (text, images, logos, design) on the Website is owned or licensed by Modello Construction and is protected by copyright, trademark, or other intellectual property laws.

You may view, download, or print pages for your personal, non-commercial use.

You may not copy, reproduce, distribute, modify, or create derivative works without our prior written permission.

You must not use the Website for unlawful or prohibited purposes.

3. Service Proposals, Contracts & Estimates

Any proposal, quote, or estimate provided is non-binding until a formal written contract is signed.

Unless otherwise stated, quotes are valid for [30/60] days from issuance.

Site conditions, code changes, material costs, or unforeseen issues may cause modifications and change orders.

All change orders must be documented in writing and agreed by both parties.

4. Payments & Billing

You agree to pay all fees, costs, and expenses outlined in the contract.

Payment schedules (deposit, milestone payments, final payment) will be defined in the contract.

Late payments may incur interest or suspension of work until you bring your account current.

You are responsible for additional costs (permitting, inspections, site access, etc.) unless otherwise stated.

5. Client Obligations

You agree to:

Provide accurate project information, drawings, and access to site

Obtain any required approvals, permits, or easements (unless included as part of our scope)

Communicate issues or changes promptly

Provide timely feedback and decisions

Ensure a safe, clean, and accessible site (except where we have responsibility per contract)

6. Warranties & Disclaimers

We warrant that our work will be performed in a professional and workmanlike manner, consistent with industry standards.

Our warranty does not cover damage from misuse, neglect, acts of God, or unauthorized modifications.

The Website and content are provided “as is”. We disclaim all warranties, express or implied, including merchantability, fitness for a particular purpose, or non-infringement of third-party rights.

7. Limitation of Liability

To the fullest extent permitted by law, Modello Construction is not liable for:

Indirect, incidental, special, punitive, or consequential damages

Loss of profits, revenue, data, or business interruption

Costs resulting from delays, defects, errors, or omissions, except to the extent of our indemnity obligations as defined in the contract

Our total aggregate liability under or relating to these Terms or the contract shall not exceed the total amount you have paid us.

8. Indemnification

You agree to indemnify, defend, and hold us, our officers, directors, employees, agents, subcontractors, and affiliates harmless from any claims, liabilities, losses, damages, or expenses (including reasonable attorney’s fees) arising out of or related to:

Your breach of these Terms

Your negligence or willful misconduct

Inaccurate or incomplete project information you provided

Violations of applicable laws or third-party rights

9. Termination / Suspension

We may suspend or terminate work or services if you fail to pay invoices, breach contract terms, or interfere with project progress.

You may terminate subject to contract terms (e.g. notice period, payment of work performed to date).

Upon termination, you pay for all work completed, materials procured, and costs incurred to the date of termination.

10. Dispute Resolution & Governing Law

These Terms and any contract shall be governed by the laws of the State of Texas (or whichever jurisdiction your business is in).

Any disputes shall first be attempted to resolve via good-faith negotiation or mediation.

If unresolved, disputes may be brought in the courts of [appropriate county / jurisdiction].

11. Severability

If any provision of these Terms is found invalid or unenforceable, that provision will be struck, and the remaining provisions will remain in full force and effect.

12. Changes to Terms

We may revise these Terms from time to time. The “Last Updated” date at the top will be updated. Continuing to use our services or website after changes constitutes acceptance of the revised Terms.

13. Contact Information

For questions about these Terms or to contact us:

Modello Construction
Address: 7666 Bandera Rd, San Antonio, Texas 78238
Email: [email protected]
Phone: (210) 319-9776